Terms and Conditions

Please read these Terms and Conditions carefully before using the All Energy Solar website or services. By accessing or using our services, you agree to be bound by these Terms. If you do not agree with any part of these terms, you may not use our services.

1. Services

All Energy Solar provides residential and commercial solar installation services, including project management, scheduling, permitting, installation, and post-installation support. Use of our website and customer communications are subject to these Terms.

2. Use of Website

You agree to use our website only for lawful purposes. You must not use the site in any way that violates applicable local, state, national, or international laws or regulations.

3. SMS / Text Messaging Program

Program Name: All Energy Solar Project Communications

By providing your mobile phone number and opting in, you consent to receive recurring
automated text messages (SMS/MMS) from All Energy Solar regarding your solar installation
project. Message types include:

• Project status updates and milestone notifications
• Scheduled appointment reminders and confirmations
• Document signature requests
• Project scope change discussions and approvals

Message Frequency: Message frequency varies based on project activity.
Costs: Message and data rates may apply. Check with your mobile carrier for details.

To opt out: Reply STOP to any message at any time to unsubscribe. You will receive a one-
time confirmation and no further messages will be sent.
For help: Reply HELP to any message, or contact us at info@allenergysolar.com.

Consent to receive SMS messages is not a condition of purchasing our services. You may opt
out at any time without affecting your solar installation project.

Carrier Disclaimer: Mobile carriers are not liable for delayed or undelivered messages. All
Energy Solar is not responsible for any delays or failures in message delivery, as transmission
is subject to effective transmission by your mobile carrier.

Privacy: Your mobile number and SMS opt-in data will not be shared with third parties for marketing purposes. For full details, see our Privacy Policy at www.allenergysolar.com/privacy-policy.

4. Intellectual Property

All content on the All Energy Solar website, including text, graphics, logos, and images, is the property of All Energy Solar and is protected by applicable intellectual property laws. You may
not reproduce or distribute any content without our express written permission.

5. Limitation of Liability

All Energy Solar shall not be liable for any indirect, incidental, special, or consequential
damages arising from the use of our website or services. Our total liability for any claim related
to our services shall not exceed the amount paid by you for the services giving rise to the claim.

6. Governing Law

These Terms and Conditions are governed by and construed in accordance with the laws of the State of Minnesota. Any disputes relating to these terms will be subject to the exclusive jurisdiction of the courts of Minnesota.

7. Changes to These Terms

All Energy Solar reserves the right to update or modify these Terms and Conditions at any time.
Changes will be effective immediately upon posting to our website. We encourage you to review
these Terms periodically. Continued use of our services after any changes constitutes your acceptance of the new Terms.

8. Contact Us

If you have any questions about these Terms and Conditions, please contact us:

All Energy Solar
Email: info@allenergysolar.com
Website: www.allenergysolar.com